Welcome to Unique Pergolas. By accessing or using our website or services, you agree to be bound by the following terms and conditions. Please read them carefully.
Products and Services:
Our company offers a variety of self-install pergola kits. All products and services are subject to availability.
Pricing and Payment:
Order Fulfillment:
Orders will be processed in the order in which they are received. We will make every effort to fulfil orders in a timely manner, but cannot guarantee delivery dates due to factors beyond our control, such as weather conditions or supply chain disruptions.
Self-Installation:
Our pergolas are designed for self-installation by customers. We provide detailed instructions for installation, as well as customer support to assist with any questions or issues that may arise during the installation process.
Liability:
We will not be liable for any damages, whether direct, indirect, incidental, special, or consequential, arising out of or in connection with the installation or use of our products. Customers assume all liability and responsibility for the installation and use of our products and should ensure that all safety precautions are taken.
Governing Law and Jurisdiction:
These terms and conditions shall be governed by and construed in accordance with the laws of the state of Victoria. Any disputes arising from or related to these terms and conditions shall be subject to the exclusive jurisdiction of the courts of Victoria.
Amendments:
We reserve the right to modify these terms and conditions at any time. Any changes will be posted on our website and will take effect immediately upon posting. Your continued use of our website or services after any changes to these terms and conditions constitutes your acceptance of the revised terms.